Platte River Bank Repair
This solicitation is RESTRICTED TO SMALL BUSINESS PARTICIPATION.
A site visit date and time will be issued with the advertisement package.
DO NOT submit requests for plans and specifications to the site visit personnel listed above. See ‘Obtaining Solicitation Documents' below.
_________________________________________________________
Project Description: (Approx. quantities)
A construction project will be conducted on the right descending bank of the Platte River located at approximately 1 river mile upstream of the Missouri River confluence near Plattsmouth, NE. The project will consist of constructing haul road access and the placement of rock riprap and random fill within an open breach of the right bank that occurred in the March 2019 flood. Quantities are projected to be less than 15,000 tons rock riprap, less than 75,000 cubic yards of random fill from on-site borrow source, topsoil and seeding, and approximately 1 mile of haul road surfacing.
The contract duration will be 60 calendar days after receipt of Notice to Proceed. It is anticipated that this project will be awarded on or before 31 December 2019 with a completion date on or before 1 March 2020.
The estimated construction cost of this project is between $1,000,000 and $5,000,000.
The Contractor will be required to commence work within 10 days after notice to proceed and complete the work 60 calendar days after receipt of Notice to Proceed. Provisions will be included for liquidated damages in case of failure to complete the work in the time allowed. Performance and payment bonds will be required. Bonding documents including the power of attorney shall bear an original signature by an officer of the surety.
Bidders (Offerors):
Please be advised of on-line registration requirement for Representations and Certifications Application (ORCA) is now located in System for Award Management (SAM) database https://www.sam.gov/portal/public/SAM/. Representations and certifications are required to be updated annually as a minimum to keep information current, accurate and complete. The electronic annual representations and certifications are effective until one year from date of submission or update to SAM.
Obtaining Solicitation Documents:
Solicitation documents will be posted to the web via Federal Business Opportunities (www.fbo.gov).
Find solicitation announcement in Fed Biz Opps (www.fbo.gov)
1. Use the ‘Quick Search' to locate the project (by entering the solicitation number) or use the advanced search features offered in the ‘Find Opportunities' (large arrow in the middle of the page) or use the ‘Opportunities' tab followed by the ‘Advanced Search' tab.
2. By using the ‘login' feature, it allows additional search features and allows you to keep your searches. Login might be required on some solicitations that are considered restricted.
3. Once you have located your project, click on link to solicitation to view the project. Files may be downloaded from the column on the right side reading ‘All Files' or from the ‘Packages' tab.
4. If you want other vendors, sub-contractors or contractors to contact you, click on the ‘Interested Vendors' tab and then ‘Add me to Interested Vendors' link at the bottom of the page.
Questions regarding contractual matters should be made to: Lynne Reed 402 995 2039. Telephone calls regarding Small Business matters should be made to: 402 995 2910.
Lynne D. Reed, Contracting Specialist, Phone 4029952039, Email lynne.d.reed@usace.army.mil - Lee M Mccormick, Contracting Officer, Phone 402-995-2084, Email lee.m.mccormick@usace.army.mil
