Chiller Replacement
Constructions Contract for. two (2) chillers Removal & Installation at the US Courthouse and Federal Office building in Midland, Texas
The Solicitation
Notice to Offerors of [Total Small Business Set-Aside
The General Services Administration (GSA) is setting aside the contract under the following clause found in the Agreement:
52.219-6, Notice of Total Small Business Set Aside
Notice of Commercial Package Carriers
Because of increased security standards, commercial package carriers may experience delays in making deliveries to the address designated for receipt of offers. United States Mail delivered to Government offices in the Washington, DC area is subject to irradiation, significantly delaying deliveries and potentially damaging or defacing mail contents. Offerors should take these facts into consideration when determining how and when to transmit offers to the office designated for receipt.
Table of Contents
I. General Information
A. The Solicitation and Contract
B. List of Solicitation Documents
C. Authorized Representatives
D. Pre-Proposal Conference
E. Estimated Price Range
F. FAR 52.228-1 Bid Guarantee
G. FAR 52.236-27 Site Visit - Construction
H. Receipt of Offers
II. Proposals
A. Proposal Contents
B. Proposal Format
C. Price Proposal
D. Technical Proposal
E. Other Information to be Submitted with Proposal
F. Requirements of Joint Venture Offerors
III. General Provisions
A. Availability of Funds
B. Requests for Clarification or Interpretation
C. Notice to Small Business Firms
D. Information Concerning the Disclosure of Solicitation Results
E. Affirmative Procurement Program
F. Notice Concerning Preparation of Proposals
G. Contractor Performance Information
H. Safeguarding Documents Designated as Sensitive But Unclassified
IV. FAR/GSAR Solicitation Provisions
A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR 101-29
B. FAR 52.211-3, Availability of Specifications Not Listed in the GSA Index of Federal Specifications, Standards and Commercial Items Description
C. FAR 52.216-1 Type Of Contract
D. FAR 52.222-5 Construction Wage Rate Requirements-Secondary Site of Work
E. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction
F. FAR 52.225-10 Notice of Buy American Requirement-Construction Materials
G. Buy American Exceptions
H. FAR 52.233-2 Service of Protest
I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference
J. GSAR 552.102 Incorporating Provisions and Clauses by Reference
K. Additional Provisions
L. Certified Cost or Pricing Data
V. Instructions to Offerors and Clauses
A. FAR 52.215-1 Instructions to Offerors - Competitive Acquisition
B. FAR 52.219-14 Limitations on Subcontracting
C. FAR 52.219-18 Notice of Competition Limited to 8(a) Eligible Participants
D. FAR 52.223-21, FOAMS (Jun 2016)
E. FAR 52.222-62 Paid Sick Leave Under Executive Order 13706
F. Security Requirements
G. Additional Clauses
VI. Method Of Award
A. Evaluation of Offers - Lowest Price Technically Acceptable
B. Lowest Price Technically Acceptable Process
C. Determination of Responsibility
D. Price Reasonableness/Price Realism
E. Unbalanced Price
F. Non Price Factors
G. Evaluation of Joint Ventures
I. General Information
I.A. The Solicitation and Contract
(1) This Solicitation is set-aside for Small Businesses, in accordance with FAR 19. This Solicitation sets forth requirements for proposals for a Contract to construct the Project described in the attached Agreement. Proposals conforming to the Solicitation requirements will be evaluated in accordance with the Method of Award set forth herein. The Government will award the Contract to the selected Offeror, subject to the conditions set forth herein.
(2) Neither the Solicitation nor any part of an Offeror's proposal shall be part of the Contract except to the extent expressly incorporated therein by the Contracting Officer.
(3) The Offeror's proposal submitted in response to this Solicitation shall constitute a firm offer. No contract shall be formed unless and until the Contracting Officer has countersigned the SF 1442 submitted by an Offeror, and delivered to the Contractor a copy of the SF 1442 with original signatures together with the Agreement reflecting the Offeror's proposed prices.
I.B. List of Solicitation Documents
The Solicitation Documents are comprised of:
(1) The Solicitation
(2) Offeror Representations and Certifications Form
(3) Standard Form (SF) 1442 - Solicitation Offer and Award
(4) The Agreement and Attachments to the Agreement
(5) Past Performance Questionnaire
(6) GSA Form 527 Contractor's Qualifications and Financial Information
I.C. Authorized Representatives
The following individuals are designated as the authorized GSA representatives under this Solicitation:
Authorized Representative Information:
Contracting Officer's Information
Name: Brian Dwyer
Address: 819 Taylor Street Rm 12B01, Fort Worth, TX 76102
Telephone: (817)-978-7336
Email: brian.dwyer@gsa.gov
Alternate POC Information
Name: Contract Specialist L. H. Lee
Address: 819 Taylor Street Rm 12B01, Fort Worth, TX 76102
Telephone: (817)-850-5535
Email: lh.lee@gsa.gov
I.D. Pre-Proposal Conference
Date: September 6, 2018
Time: 1:30 pm CST
Location: : Federal Building/Courthouse
200 E. Wall Street
Midland. TX 797001
I.E. Estimated Price Range
The estimated price range for the Project is between $ 500,000.00 and $1,000,000.00
I.F. FAR 52.228-1 Bid Guarantee (Sep 96)
(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.
(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-
(1) To unsuccessful bidders as soon as practicable after the opening of bids; and
(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.
(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.
(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.
(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.
I.G. FAR 52.236-27 Site Visit - Construction (FEB 95)
(1) The clauses at FAR 52.236-2, Differing Site Conditions, and FAR 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, Offerors are urged and expected to inspect the site where the work will be performed.
(3) Pre-registration is required for all attendees to the pre-proposal Site Visit. The Site Visit shall be limited to not more than four (4) representatives from each Offeror. Offerors shall submit a Visit Authorization Request (VAR) identifying all attendees from their respective team. Participants must have a valid, Government issued picture identification, driver's license preferred, to gain access for the pre-proposal Site Visit. Notification of the location of entry, where attendees are required to meet, and all other requirements for the Site Visit will be issued to the Offerors. Submit the VAR to the point of contact listed below.
(2) Site visits will be held at the following dates and times:
Date: September 6, 2018
Time: 1:30 pm CST
For further information about the site visit or access requirements, please contact:
Name: Sha'Mar Nolen, Project Manager
Email: sha'mar.nolen@gsa.gov
Phone: (817) 850-8283
I.H. Receipt of Offers
(1) In order to be considered for award, offers conforming to the requirements of the Solicitation must be received at the following office no later than 2:00 pm local time on the following date and at the following address.
Date: September 28, 2018
Address: Brian Dwyer, 7PQD
Fritz G. Lanham Federal Building
GSA-PBS Acquisition Services
819 Taylor Street 12-B01
Fort Worth Worth, TX 76102
Solicitation 47PH1118R0010
OR BY EMAIL to lh.lee@gsa.gov
(2) Offers sent by commercial package delivery and hand delivery shall be deemed received as of the date and time of delivery to the office designated for receipt of offers.
(3) Offers sent by United States Mail shall be deemed timely if delivered to the address of the government installation designated for receipt of offers on or before the date established for receipt of offers.
II. Proposals
II.A. Proposal Contents
Proposals shall consist of the following documents, completed and executed in accordance with this Solicitation:
1. Price Proposal
2. Technical Proposal
3. Representations and Certifications
4. Standard Form 24, Bid Bond
5. GSA Form 527 - Contractor's Qualification and Financial Information
6. Past Performance Questionnaire
II.B. Proposal Format
Offerors are required to submit one (1) original and two (2) copies of their technical proposal. All materials submitted shall be in typeface Times New Roman, 12 point, single spaced on 8-1/2" X 11" white paper with half inch margins all around, and printed on both sides (exclusive of resumes, certificate copies, etc.). The technical proposal shall not exceed 35 pages (double sided).
Offerors are also required to submit a separate pricing proposal - one (1) original and one (1) copy. The Contractor shall provide a base quote (page 3 of the SF1442) with a detailed cost breakout. Cost breakout shall be formatted per the Construction Specification Institute (CSI) divisions of work breakdown. The cost breakout shall sum to the total construction cost of the quote.
Electronic proposals are required to be submitted in two volumes: Technical and Price via email to lh.lee@gsa.gov.
II.C. Price Proposal
(1) Contents
The Price Proposal shall consist of the SF 1442 and the Agreement, with prices and/or rates indicated for each price element shown on the pricing form included in Section II of the Agreement. Indicate the Base Contract Price, or if no such distinction is made, the Contract Price, in Block 17 of the SF 1442, which must be fully executed by the Offeror.
(2) Qualifications, Exclusions and Conditions
If the Offeror communicates in its proposal any qualifications, exclusions, or conditions to the proposed prices not provided for in the Contract Documents, the Contracting Officer may reject the proposal and exclude the Offeror from further discussions.
(3) Additional Proposal Requirements
NA
II.D. Technical Proposal
The Technical Proposal shall include the information requested below for the non-price factors described in Section VI.
(1) Experience on Similar Projects
This factor evaluates the extent of the Offeror's past experience as a firm in providing similar construction services to determine the firm's experience in completing the tasks detailed in the performance work statement.
The Offeror must demonstrate successful experience as a General Construction (GC) Contractor responsible for the construction of at least two (2) similar projects substantially completed within the last five (5) years. A "similar project" is defined as a project that is comparable in nature, type, and complexity as defined by all of the following characteristics:
● Project involved the renovation or the modernization of a comparably sized structure;
● Project was performed in an occupied and functioning office building;
● Project involved all of the following disciplines HVAC,
● Project included requirements for noise control
The total project construction cost at award of the construction contract(s) was not less than $500,000.00
● Attachment A shall be used for each project.
(2) Content of Price proposal
This factor considers the extent of the Offeror's understanding as a firm of the materials and activities necessary to successfully complete the project as described.
II.E. Other Information to Submit with Proposal
(1) Representations and Certifications
Offerors submitting a proposal in response to this Solicitation shall complete electronic Annual Representations and Certifications in conjunction with required Entity registration in System for Award Management (SAM), accessed via System for Award Management. Offerors shall also submit with their proposal, the Annual Representations and Certifications (FAR 52.204-8), using the attached Offeror's Representations and Certifications (C301-SAT).
(2) Qualifications of Offerors
Offerors submitting a proposal in response to this Solicitation shall submit with their proposal evidence of their financial responsibility and capacity to perform the Contract. Offerors shall submit this information on GSA Form 527 - Contractor's Qualifications and Financial Information. Where applicable, point of contact, including names and telephone numbers, are required for all contracts listed.
II.F. Requirements of Joint Venture Offerors
(1) All offers submitted by joint ventures must include a copy of an executed joint venture agreement (with original signatures) which fully discloses the legal identity of each member of the joint venture, the relationship between the members, the form of ownership of each member, and any limitations on liability or authority for each member.
(2) An authorized representative of each member of the joint venture must sign the SF 1442 accompanying an offer regardless of any agency relationship established between the members.
(3) In the case of corporations that are joint venture members, the corporation secretary must certify that the corporation is authorized to participate in the joint venture, either by so certifying in the joint venture agreement, or by submitting a separate certification to the Government. The joint venture must also provide a certificate that identifies a principal representative of the joint venture with full authority to bind the joint venture.
(4) Representations and certifications, financial information, and past performance information must be submitted for each member of the joint venture.
III. General Provisions
III.A. Availability of Funds
Issuance of this Solicitation does not warrant that funds are presently available for award of a Contract. Award of the contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under this Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award.
III.B. Requests for Clarification or Interpretation
The Government will attempt to answer all requests for clarifications or interpretations of the Solicitation Documents prior to the date set for receipt of offers, but do not warrant that all such requests will be answered within 10 calendar days. Prospective Offerors should make such requests not less than 15 calendar days prior to the date set for receipt of offers.
III.C. Notice to Small Business Firms
A program for the purpose of assisting qualified small business concerns in obtaining certain bid, payment, or performance bonds that are otherwise not obtainable is available through the Small Business Administration (SBA) (Small Business Administration). For information concerning SBA's surety bond guarantee assistance, contact your SBA District Office.
III.D. Information Concerning the Disclosure of Solicitation Results
This acquisition is being conducted under the provisions of FAR Part 15 as a negotiated procurement. In accordance with FAR 3.104 and FAR 15.207, after receipt of proposals, no information regarding the identity of those submitting offers, the number of offers received, or the information contained in such offers will be made available until after award except as provided by FAR 15.503.
III.E. Affirmative Procurement Program
GSA has implemented an Affirmative Procurement Program (APP) intended to maximize the use of recovered materials, environmentally preferable, and bio-based products. Offerors should familiarize themselves with the requirements for using and reporting on the use of such materials in performance as set forth in the Agreement. Refer to Clause FAR 52.223-10 encouraging vendors to practice waste reduction.
III.F. Notice Concerning Preparation of Proposals
Offerors are cautioned to carefully read the entire Solicitation and the Agreement to be included in the Contract contemplated by the Solicitation in order to be fully aware of all requirements and clauses in the contemplated Contract. Verify that all blanks requiring information to be supplied in an Offer have been properly filled out, that all pricing and other numerical data is accurately calculated, and that all copies of the Offer contain the same information.
III.G. Contractor Performance Information
(1) Evaluating Contractor Performance: The General Services Administration is using the Contractor Performance Assessment Reporting System (CPARS) module as the secure, confidential, information management tool to facilitate the performance evaluation process. CPARS enables a comprehensive evaluation by capturing comments from both GSA and the contractor. The website for CPARS is Contractor Performance Assessment
Completed CPARS evaluations are sent to the Past Performance Information Retrieval System (PPIRS) which may then be used by Federal acquisition community for use in making source selection decisions. PPIRS assists acquisition officials by serving as the single source for contractor past performance data.
(2) CPARS Registration: Each award requiring an evaluation must be registered in CPARS. The contractor will receive several automated emails. Within thirty days of award, the contractor will receive an e-mail that contains user account information, as well as the applicable contract and order number(s) assigned. Contractors will be granted one user account to access all evaluations.
(3) Contractor CPARS Training: Contractors may sign up for CPARS training. A schedule of classes will be posted to the CPARS training site (CPARS Training) and updated as needed.
(4) Contractor Representative (CR) Role: All evaluations will be sent the Contractor Representative (CR) named on your award. The CR will be able to access CPARS to review and comment on the evaluation. If your CR is not already in the CPARS system, the contracting officer will request the name and email address of the person that will be responsible for the CR role on your award.
Once an evaluation is ready to be released the CR will receive an email alerting them the evaluation is ready for their review and comment. The email will indicate the time frame the CR has to respond to the evaluation; however, the CR may return the evaluation earlier than this date.
GSA shall provide for review at a level above the contracting officer (i.e., contracting director) to consider any disagreement between GSA and the contractor regarding GSA's evaluation of the contractor. Based on the review, the individual at a level above the contracting officer will issue the ultimate conclusion on the performance evaluation.
Copies of the evaluations, contractor responses, and review comments, if any, will be retained as part of the contract file.
III.H. Safeguarding Documents Designated as Sensitive But Unclassified
Certain information contained in the Solicitation Documents may have been designated as Sensitive but Unclassified (SBU) building information. With respect to such information, Offerors shall agree to the terms for receipt of such information, as set forth in the provision "Administrative Matters" in Section III of the Agreement, as a condition of receipt of such information.
IV. FAR/GSAR Solicitation Provisions
IV.A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29 (AUG 98)
(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to-
GSA Federal Supply Service
Specifications Section, Suite 8100
470 East L'Enfant Plaza, SW
Washington, DC 20407
Telephone (202) 619-8925
Facsimile (202) 619-8978
(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision. Additional copies will be issued for a fee.
IV.B. FAR 52.216-1 Type of Contract (APR 84)
The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.
IV.C. FAR 52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work (MAY 14)
(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.
(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.
(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.
(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.
IV.D. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999)
(Applicable to solicitations resulting in construction contracts in excess of $10,000.)
(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.
(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:
Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade
19.1% 6.9%
These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.
(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.
(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the--
(1) Name, address, and telephone number of the subcontractor;
(2) Employer's identification number of the subcontractor;
(3) Estimated dollar amount of the subcontract;
(4) Estimated starting and completion dates of the subcontract; and
(5) Geographical area in which the subcontract is to be performed.
(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is: State ofTexas, County of Midland, City of Midland.
IV.E. FAR 52.225-10 Notice of Buy American Requirement-Construction Materials. (MAY 2014)
(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).
(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.
(c) Evaluation of offers.
(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.
(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.
(d) Alternate offers.
(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.
(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.
(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested-
(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or
(ii) May be accepted if revised during negotiations.
IV.F. Buy American Exceptions
For Buy American exceptions, if any, see the applicable Buy American clause in Section IV of the Agreement
IV.G. FAR 52.233-2 Service of Protest (SEP 06)
(a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the Contracting Officer at the address provided in the provision "Receipt of Offers" in Section I (General Information).
(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.
IV.H. FAR 52.252-1 Solicitation Provisions Incorporated by Reference (FEB 98)
This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address:
Federal Acquisition Regulation
NUMBER TITLE DATE
52.214-34 Submission of Offers in the English Language APR 91
52.215-16 Facilities Capital Cost of Money JUN 03
52.236-28 Preparation of Proposals - Construction OCT 97
IV.I. GSAR Clause 552.102 Incorporating Provisions and Clauses
This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.
V. Instructions and Clauses
V.A. FAR 52.215-1 Instructions to Offerors - Competitive Acquisition (Jan 2017)
(a) Definitions. As used in this provision.
"Discussions" are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.
"In writing," "writing," or "written" means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.
"Proposal modification" is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.
"Proposal revision" is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.
"Time," if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.
(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).
(c) Submission, modification, revision, and withdrawal of proposals.
(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.
(2) The first page of the proposal must show.
(i) The solicitation number;
(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);
(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;
(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and
(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.
(3) Submission, modification, revision, and withdrawal of proposals.
(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.
(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and.
(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or
(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or
(3) It is the only proposal received.
(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.
(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.
(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.
(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.
(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.
(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.
(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.
(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.
(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.
(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).
(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall.
(1) Mark the title page with the following legend:
This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed.in whole or in part.for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of.or in connection with.the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and
(2) Mark each sheet of data it wishes to restrict with the following legend:
Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.
(f) Contract award.
(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.
(2) The Government may reject any or all proposals if such action is in the Government's interest.
(3) The Government may waive informalities and minor irregularities in proposals received.
(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.
(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.
(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.
(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.
(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.
(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.
(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.
(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:
(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.
(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.
(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.
(iv) A summary of the rationale for award.
(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.
(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.
V.B. FAR 52.219-14 Limitations on Subcontracting (JAN 2017)
(b) Applicability. This clause applies only to--
(1) Contracts that have been set aside or reserved for small business concerns or 8(a) participants;
(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; and
(3) Orders set aside for small business or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).
(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for --
(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.
(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.
V.C. FAR 52.223-21, FOAMS (JUN 2016)
FOAMS (JUN 2016)
(a) Definitions. As used in this clause-
"Global warming potential" means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide's global warming potential is defined as 1.0.
"High global warming potential hydrofluorocarbons" means any hydrofluorocarbons in a particular end use for which EPA's Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82 subpart G with supplemental tables of alternatives available at http://www.epa.gov/snap/.
"Hydrofluorocarbons" means compounds that contain only hydrogen, fluorine, and carbon.
(b) Unless otherwise specified in the contract, the Contractor shall reduce its use, release, and emissions of high global warming potential hydrofluorocarbons and refrigerant blends containing hydrofluorocarbons, when feasible, from foam blowing agents, under this contract. When determining feasibility of using a particular alternative, the Contractor shall consider environmental, technical, and economic factors such as-
(1) In-use emission rates, energy efficiency, and safety;
(2) Ability to meet performance requirements; and
(3) Commercial availability at a reasonable cost.
(c) The Contractor shall refer to EPA's SNAP program to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82 subpart G with supplemental tables available at http://www.epa.gov/snap/.
V.D. FAR 52.222-62, Paid Sick Leave under Executive Order 13706 (JAN 2017)
Paid Sick Leave Under Executive Order 13706 (Jan 2017)
(a) Definitions. As used in this clause (in accordance with 29 CFR 13.2)-
"Child", "domestic partner", and "domestic violence" have the meaning given in 29 CFR 13.2.
"Employee"-
(1)(i) Means any person engaged in performing work on or in connection with a contract covered by Executive Order (E.O.) 13706, and
(A) Whose wages under such contract are governed by the Service Contract Labor Standards statute (41 U.S.C. chapter 67), the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV), or the Fair Labor Standards Act (29 U.S.C. chapter 8),
(B) Including employees who qualify for an exemption from the Fair Labor Standards Act's minimum wage and overtime provisions,
(C) Regardless of the contractual relationship alleged to exist between the individual and the employer; and
(ii) Includes any person performing work on or in connection with the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor's Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.
(2)(i) An employee performs "on" a contract if the employee directly performs the specific services called for by the contract; and
(ii) An employee performs "in connection with" a contract if the employee's work activities are necessary to the performance of a contract but are not the specific services called for by the contract.
"Individual related by blood or affinity whose close association with the employee is the equivalent of a family relationship" has the meaning given in 29 CFR 13.2.
"Multiemployer" plan means a plan to which more than one employer is required to contribute and which is maintained pursuant to one or more collective bargaining agreements between one or more employee organizations and more than one employer.
"Paid sick leave" means compensated absence from employment that is required by E.O. 13706 and 29 CFR part 13.
"Parent", "sexual assault", "spouse", and "stalking" have the meaning given in 29 CFR 13.2.
"United States" means the 50 States and the District of Columbia.
(b) Executive Order 13706.
(1) This contract is subject to E.O. 13706 and the regulations issued by the Secretary of Labor in 29 CFR part 13 pursuant to the E.O.
(2) If this contract is not performed wholly within the United States, this clause only applies with respect to that part of the contract that is performed within the United States.
(c) Paid sick leave. The Contractor shall-
(1) Permit each employee engaged in performing work on or in connection with this contract to earn not less than 1 hour of paid sick leave for every 30 hours worked;
(2) Allow accrual and use of paid sick leave as required by E.O. 13706 and 29 CFR part 13;
(3) Comply with the accrual, use, and other requirements set forth in 29 CFR 13.5 and 13.6, which are incorporated by reference in this contract;
(4) Provide paid sick leave to all employees when due free and clear and without subsequent deduction (except as otherwise provided by 29 CFR 13.24), rebate, or kickback on any account;
(5) Provide pay and benefits for paid sick leave used no later than one pay period following the end of the regular pay period in which the paid sick leave was taken; and
(6) Be responsible for the compliance by any subcontractor with the requirements of E.O. 13706, 29 CFR part 13, and this clause.
(d) Contractors may fulfill their obligations under E.O. 13706 and 29 CFR part 13 jointly with other contractors through a multiemployer plan, or may fulfill their obligations through an individual fund, plan, or program (see 29 CFR 13.8).
(e) Withholding. The Contracting Officer will, upon his or her own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the Contractor under this or any other Federal contract with the same Contractor, so much of the accrued payments or advances as may be considered necessary to pay employees the full amount owed to compensate for any violation of the requirements of E.O. 13706, 29 CFR part 13, or this clause, including-
(1) Any pay and/or benefits denied or lost by reason of the violation;
(2) Other actual monetary losses sustained as a direct result of the violation; and
(3) Liquidated damages.
(f) Payment suspension/contract termination/contractor debarment.
(1) In the event of a failure to comply with E.O. 13706, 29 CFR part 13, or this clause, the contracting agency may, on its own action or after authorization or by direction of the Department of Labor and written notification to the Contractor take action to cause suspension of any further payment, advance, or guarantee of funds until such violations have ceased.
(2) Any failure to comply with the requirements of this clause may be grounds for termination for default or cause.
(3) A breach of the contract clause may be grounds for debarment as a contractor and subcontractor as provided in 29 CFR 13.52.
(g) The paid sick leave required by E.O. 13706, 29 CFR part 13, and this clause is in addition to the Contractor's obligations under the Service Contract Labor Standards statute and Wage Rate Requirements (Construction) statute, and the Contractor may not receive credit toward its prevailing wage or fringe benefit obligations under those Acts for any paid sick leave provided in satisfaction of the requirements of E.O. 13706 and 29 CFR part 13.
(h) Nothing in E.O. 13706 or 29 CFR part 13 shall excuse noncompliance with or supersede any applicable Federal or State law, any applicable law or municipal ordinance, or a collective bargaining agreement requiring greater paid sick leave or leave rights than those established under E.O. 13706 and 29 CFR part 13.
(i) Recordkeeping
(1) The Contractor shall make and maintain, for no less than three (3) years from the completion of the work on the contract, records containing the following information for each employee, which the Contractor shall make available upon request for inspection, copying, and transcription by authorized representatives of the Administrator of the Wage and Hour Division of the Department of Labor:
(i) Name, address, and social security number of each employee.
(ii) The employee's occupation(s) or classification(s).
(iii) The rate or rates of wages paid (including all pay and benefits provided).
(iv) The number of daily and weekly hours worked.
(v) Any deductions made.
(vi) The total wages paid (including all pay and benefits provided) each pay period.
(vii) A copy of notifications to employees of the amount of paid sick leave the employee has accrued, as required under 29 CFR 13.5(a)(2).
(viii) A copy of employees' requests to use paid sick leave, if in writing, or, if not in writing, any other records reflecting such employee requests.
(ix) Dates and amounts of paid sick leave taken by employees (unless the Contractor's paid time off policy satisfies the requirements of E.O. 13706 and 29 CFR part 13 as described in 29 CFR 13.5(f)(5), leave shall be designated in records as paid sick leave pursuant to E.O. 13706).
(x) A copy of any written responses to employees' requests to use paid sick leave, including explanations for any denials of such requests, as required under 29 CFR 13.5(d)(3).
(xi) Any records reflecting the certification and documentation the Contractor may require an employee to provide under 29 CFR 13.5(e), including copies of any certification or documentation provided by an employee.
(xii) Any other records showing any tracking of or calculations related to an employee's accrual or use of paid sick leave.
(xiii) The relevant contract.
(xiv) The regular pay and benefits provided to an employee for each use of paid sick leave.
(xv) Any financial payment made for unused paid sick leave upon a separation from employment intended, pursuant to 29 CFR 13.5(b)(5), to relieve the Contractor from the obligation to reinstate such paid sick leave as otherwise required by 29 CFR 13.5(b)(4).
(2)(i) If the Contractor wishes to distinguish between an employee's covered and noncovered work, the Contractor shall keep records or other proof reflecting such distinctions. Only if the Contractor adequately segregates the employee's time will time spent on noncovered work be excluded from hours worked counted toward the accrual of paid sick leave. Similarly, only if the Contractor adequately segregates the employee's time may the Contractor properly refuse an employee's request to use paid sick leave on the ground that the employee was scheduled to perform noncovered work during the time he or she asked to use paid sick leave.
(ii) If the Contractor estimates covered hours worked by an employee who performs work in connection with contracts covered by the E.O. pursuant to 29 CFR 13.5(a)(i) or (iii), the Contractor shall keep records or other proof of the verifiable information on which such estimates are reasonably based. Only if the Contractor relies on an estimate that is reasonable and based on verifiable information will an employee's time spent in connection with noncovered work be excluded from hours worked counted toward the accrual of paid sick leave. If the Contractor estimates the amount of time an employee spends performing in connection with contracts covered by the E.O., the Contractor shall permit the employee to use his or her paid sick leave during any work time for the Contractor.
(3) In the event the Contractor is not obligated by the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, or the Fair Labor Standards Act to keep records of an employee's hours worked, such as because the employee is exempt from the Fair Labor Standards Act's minimum wage and overtime requirements, and the Contractor chooses to use the assumption permitted by 29 CFR 13.5(a)(1)(iii), the Contractor is excused from the requirement in paragraph (i)(1)(iv) of this clause and 29 CFR 13.25(a)(4) to keep records of the employee's number of daily and weekly hours worked.
(4)(i) Records relating to medical histories or domestic violence, sexual assault, or stalking, created for purposes of E.O. 13706, whether of an employee or an employee's child, parent, spouse, domestic partner, or other individual related by blood or affinity whose close association with the employee is the equivalent of a family relationship, shall be maintained as confidential records in separate files/records from the usual personnel files.
(ii) If the confidentiality requirements of the Genetic Information Nondiscrimination Act of 2008 (GINA), section 503 of the Rehabilitation Act of 1973, and/or the Americans with Disabilities Act (ADA) apply to records or documents created to comply with the recordkeeping requirements in this contract clause, the records and documents shall also be maintained in compliance with the confidentiality requirements of the GINA, section 503 of the Rehabilitation Act of 1973, and/or ADA as described in 29 CFR 1635.9, 41 CFR 60-741.23(d), and 29 CFR 1630.14(c)(1), respectively.
(iii) The Contractor shall not disclose any documentation used to verify the need to use 3 or more consecutive days of paid sick leave for the purposes listed in 29 CFR 13.5(c)(1)(iv) (as described in 29 CFR 13.5(e)(1)(ii)) and shall maintain confidentiality about any domestic abuse, sexual assault, or stalking, unless the employee consents or when disclosure is required by law.
(5) The Contractor shall permit authorized representatives of the Wage and Hour Division to conduct interviews with employees at the worksite during normal working hours.
(6) Nothing in this contract clause limits or otherwise modifies the Contractor's recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, the Family and Medical Leave Act, E.O. 13658, their respective implementing regulations, or any other applicable law.
(j) Interference/discrimination.
(1) The Contractor shall not in any manner interfere with an employee's accrual or use of paid sick leave as required by E.O. 13706 or 29 CFR part 13. Interference includes, but is not limited to-
(i) Miscalculating the amount of paid sick leave an employee has accrued;
(ii) Denying or unreasonably delaying a response to a proper request to use paid sick leave;
(iii) Discouraging an employee from using paid sick leave;
(iv) Reducing an employee's accrued paid sick leave by more than the amount of such leave used;
(v) Transferring an employee to work on contracts not covered by the E.O. to prevent the accrual or use of paid sick leave;
(vi) Disclosing confidential information contained in certification or other documentation provided to verify the need to use paid sick leave; or
(vii) Making the use of paid sick leave contingent on the employee's finding a replacement worker or the fulfillment of the Contractor's operational needs.
(2) The Contractor shall not discharge or in any other manner discriminate against any employee for-
(i) Using, or attempting to use, paid sick leave as provided for under E.O. 13706 and 29 CFR part 13;
(ii) Filing any complaint, initiating any proceeding, or otherwise asserting any right or claim under E.O. 13706 and 29 CFR part 13;
(iii) Cooperating in any investigation or testifying in any proceeding under E.O. 13706 and 29 CFR part 13; or
(iv) Informing any other person about his or her rights under E.O. 13706 and 29 CFR part 13.
(k) Notice. The Contractor shall notify all employees performing work on or in connection with a contract covered by the E.O. of the paid sick leave requirements of E.O. 13706, 29 CFR part 13, and this clause by posting a notice provided by the Department of Labor in a prominent and accessible place at the worksite so it may be readily seen by employees. Contractors that customarily post notices to employees electronically may post the notice electronically, provided such electronic posting is displayed prominently on any website that is maintained by the Contractor, whether external or internal, and customarily used for notices to employees about terms and conditions of employment.
(l) Disputes concerning labor standards. Disputes related to the application of E.O. 13706 to this contract shall not be subject to the general disputes clause of the contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR part 13. Disputes within the meaning of this contract clause include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the Department of Labor, or the employees or their representatives.
(m) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (m), in all subcontracts, regardless of dollar value, that are subject to the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, and are to be performed in whole or in part in the United States.
(End of clause)
V D. Security Requirements
(1) FAR 52.204-9, Personal Identity Verification of Contractor Personnel, January 2011
(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24 and Federal Information Processing Standards Publication (FIPS PUB) Number 201.
(b) The Contractor shall account for all forms of Government-provided identification issued to the Contractor employees in connection with performance under this contract. The Contractor shall return such identification to the issuing agency at the earliest of any of the following, unless otherwise determined by the Government:
(1) When no longer needed for contract performance.
(2) Upon completion of the Contractor employee's employment.
(3) Upon contract completion or termination.
(c) The Contracting Officer may delay final payment under a contract if the Contractor fails to comply with these requirements.
(d) The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts when the subcontractor's employees are required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. It shall be the responsibility of the prime Contractor to return such identification to the issuing agency in accordance with the terms set forth in paragraph (b) of this section, unless otherwise approved in writing by the Contracting Officer.
(4) (FAR 52.224-1, Privacy Act Notification, April 1984
The Contractor will be required to design, develop, or operate a system of records on individuals, to accomplish an agency function subject to the Privacy Act of 1974, Public Law 93-579, December 31, 1974 (5 U.S.C. 552a) and applicable agency regulations.
(5) FAR 52.224-2 Privacy Act, April 1984
(
(a) The Contractor agrees to.
(1) Comply with the Privacy Act of 1974 (the Act) and the agency rules and regulations issued under the Act in the design, development, or operation of any system of records on individuals to accomplish an agency function when the contract specifically identifies.
(i) The systems of records; and
(ii) The design, development, or operation work that the contractor is to perform;
(2) Include the Privacy Act notification contained in this contract in every solicitation and resulting subcontract and in every subcontract awarded without a solicitation, when the work statement in the proposed subcontract requires the redesign, development, or operation of a system of records on individuals that is subject to the Act; and
(3) Include this clause, including this paragraph (3), in all subcontracts awarded under this contract which requires the design, development, or operation of such a system of records.
(b) In the event of violations of the Act, a civil action may be brought against the agency involved when the violation concerns the design, development, or operation of a system of records on individuals to accomplish an agency function, and criminal penalties may be imposed upon the officers or employees of the agency when the violation concerns the operation of a system of records on individuals to accomplish an agency function. For purposes of the Act, when the contract is for the operation of a system of records on individuals to accomplish an agency function, the Contractor is considered to be an employee of the agency.
(c)(1) "Operation of a system of records," as used in this clause, means performance of any of the activities associated with maintaining the system of records, including the collection, use, and dissemination of records.
(2) "Record," as used in this clause, means any item, collection, or grouping of information about an individual that is maintained by an agency, including, but not limited to, education, financial transactions, medical history, and criminal or employment history and that contains the person's name, or the identifying number, symbol, or other identifying particular assigned to the individual, such as a fingerprint or voiceprint or a photograph.
(3) "System of records on individuals," as used in this clause, means a group of any records under the control of any agency from which information is retrieved by the name of the individual or by some identifying number, symbol, or other identifying particular assigned to the ind
